Terms and Conditions for Outback Kitchens & Cabinetry

These Terms and Conditions govern your use of our services provided by Outback Kitchens & Cabinetry, including custom kitchen design, cabinet manufacturing, kitchen installation, benchtops and splashbacks, kitchen renovations, commercial kitchen fit-outs, and joinery services. By engaging with our services, you agree to comply with and be bound by these terms.

1. Acceptance of Terms

By accepting a quote, making a deposit, or otherwise engaging Outback Kitchens & Cabinetry for any service, you acknowledge that you have read, understood, and agree to these Terms and Conditions. These terms constitute a legally binding agreement between you and Outback Kitchens & Cabinetry.

2. Services Provided

Outback Kitchens & Cabinetry offers a range of services including, but not limited to:

Specific details of the services to be provided will be outlined in your individual quote or contract.

3. Quotes and Pricing

All quotes provided by Outback Kitchens & Cabinetry are valid for a period of 30 days from the date of issue unless otherwise specified. Prices quoted are based on the information and specifications provided at the time of quotation. Any changes to design, materials, or scope of work after the quote has been accepted may result in additional charges.

4. Payments

A deposit, as specified in your quote, is required to commence work. Progress payments may be required at various stages of the project, with the final balance due upon satisfactory completion of services. Payment terms will be clearly outlined in your service agreement. Failure to make payments as per the agreed schedule may result in delays or suspension of work.

5. Design and Approval

For custom design projects, Outback Kitchens & Cabinetry will provide design concepts and plans for your approval. It is your responsibility to review and approve all designs, dimensions, materials, and finishes before manufacturing commences. Once approved, any further changes may incur additional costs and affect project timelines.

6. Project Timelines

Estimated project timelines will be provided; however, these are approximations. Outback Kitchens & Cabinetry will not be liable for delays caused by factors beyond our reasonable control, including but not limited to material shortages, third-party supplier delays, unforeseen site conditions, or changes requested by the client.

7. Site Preparation and Access

For installation services, it is your responsibility to ensure the site is clear, safe, and accessible for our team and equipment. This includes removing existing fixtures, clearing pathways, and ensuring adequate power and water are available, unless otherwise agreed upon in writing.

8. Warranty and Guarantees

Outback Kitchens & Cabinetry provides warranties on our workmanship and supplied products in accordance with Australian consumer law. Specific warranty details for materials and appliances will be passed on from the respective manufacturers. Any defects or issues must be reported to us in writing within a reasonable timeframe after completion.

9. Limitation of Liability

To the fullest extent permitted by law, Outback Kitchens & Cabinetry shall not be liable for any indirect, incidental, special, consequential, or punitive damages, or any loss of profits or revenues, whether incurred directly or indirectly, or any loss of data, use, goodwill, or other intangible losses, resulting from your engagement with our services.

10. Intellectual Property

All designs, drawings, and intellectual property created by Outback Kitchens & Cabinetry in the course of providing services remain the property of Outback Kitchens & Cabinetry until full payment for the services has been received. We reserve the right to use project photos for promotional purposes, ensuring client privacy where necessary.

11. Termination of Services

Either party may terminate the service agreement under specific conditions, such as a breach of these terms. In the event of termination, you will be liable for all work performed and costs incurred up to the date of termination.

12. Governing Law

These Terms and Conditions are governed by the laws of Victoria, Australia. Any disputes arising out of or in connection with these terms shall be subject to the exclusive jurisdiction of the courts of Victoria.

13. Contact Information

For any questions, concerns, or feedback regarding these Terms and Conditions or our services, please contact us:

Outback Kitchens & Cabinetry

14 Waratah Drive,

Port Melbourne, Victoria, 3207

Australia

We use cookies to ensure you get the best experience on our website. By continuing to use this site, you agree to our Privacy Policy.